The impact of COVID-19 on the infrastructure and construction sector in India has been extensive and damaging. The restrictions imposed by the Government of India, State Governments and the Union Territories to control the spread and impact of the virus have prevented work on projects, adversely impacted supply chains, plant, equipment, materials and manpower. Delays and disruptions to completion of projects are inevitable with concomitant losses, cost and expenses. Those involved in the construction industry need to be alert to the contractual and other provisions which govern entitlements to the potential recovery of these exposures. All of such entitlements are likely to be subject to time-critical notice requirements and whilst some may be familiar with the concepts of &ldquo;force majeure&rdquo; which is enshrined in many contracts, the assertion of the occurrence of force majeure may have unintended consequences. Contractors and Employers alike therefore need to be aware of the existence of particular contractual entitlements to extensions of time to complete and for the payment of additional costs in relation to their projects. Such clauses are likely to be subject to certain conditions governing their operation. Generally speaking, no two contracts are identical and may have material differences in the way in which they approach such matters and it is therefore not possible to provide any generic contractual panacea for those involved in the construction sector. However, many EPC and other contracts in India take as their base the FIDIC forms of Viewpoint contract, in particular the &ldquo;Silver Book&rdquo; and this Note therefore focusses upon the rights and obligations prescribed by that Form in the context of the COVID problems. There will inevitably be contracts with unique changes to the FIDIC Form and this Note can only serve as a preliminary guide but one which hopefully will catalyze thinking of the steps to be taken to moderate the impact of COVID -19 and preserve and implement rights and protections under contract.COVID-19 and Force MajeureUnder Force Majeure clauses, if either party is prevented from performance of its obligations by reason of certain defined exceptional or extraordinary circumstances beyond its control, then, subject to giving notice, it may be excused performance of those obligations. Force Majeure clauses differ from contract to contract but generally provide entitlement to extensions of time and in some cases, costs. Clause 19 of FIdIC defines force majeure as (i) an &ldquo;exceptional event or circumstance&rdquo; (ii) &ldquo;which is beyond a Party&rsquo;s control&rdquo;, (iii) &ldquo;which such Party could not reasonably have provided against before entering the contract (iv) &ldquo;which, having arisen, such Party could not reasonably have avoided or overcome&rdquo; and (v) &ldquo;which is not substantially attributable to the other Party&rdquo; For the definition to be satisfied the event must be exceptional and meet the five criteria above. FIdIC then goes further by listing in sub-clauses (i) to (v) of Clause 19.1 some examples of circumstances which may amount to Force Majeure so long as they satisfy the above five criteria. The list is not exhaustive and does not include pandemic but it is generally considered that CovId-19 does satisfy the five criteria.To pursue a claim for Force Majeure requires the service of a Notice specifying the event of Force Majeure and the particular obligations whose performance is or will be, prevented. That Notice is likely to be a condition precedent to the right to claim so must be dealt with correctly. Employers who are prevented from giving access or possession to Site or supplying Employer supplied material may give Notice. Contractors suffering delayed material, plant or workforce supplies or other interruptions may also give Notice. Since at this stage in the pandemic many of such Notices may have been given, it is important now to consider the effects of such Notice, the further steps which need to be taken and alternative approaches open to the Contractors for recovering costs.The first point to be made for Contractors is the need to prove causation &ndash; that is to say that COVID and the restrictions caused the problems complained of. The pandemic may be seen by the Contract Administrator as a useful smokescreen to conceal an inherent problem which is the responsibility of the Contractor, such as a pre-pandemic failure to mobilize adequately. Contractors need to be aware of the need to prove cause and effect. Evidence in the form of Site photographs, Site Meeting minutes, communications and recollections of Site staff etc. need to be assembled to support causation and to combat any suggestion of alternatives causation which is a Contractor risk.Secondly, Contractors need to be aware that although COVID is likely (but not guaranteed) to be an event of Force Majeure, the FIDIC contract, whilst providing an entitlement to an extension of time, does not provide an entitlement to recovery of costs. This is simply because the, cost recovery is permitted only if the event falls under the very specific events identified in sub-clauses (i) to (iv), of 19.1 which do not include the pandemic. If at all, the pandemic falls under the broader wording of sub-clause (v). So Contractors must look elsewhere in the Contract for rights to recover costs.Thirdly, the FIDIC contract requires regular updates of the impact of Force Majeure as events develop. In many contracts these updates, as well as the giving of the original Notice, will be a condition precedent to the right of recovery. No notice &ndash; no right to claim!Fourthly, Employers and Contractors alike must be aware that whilst the giving of a Force Majeure Notice to prevent its nonperformance being a breach of contract, it will amount to an admission that it is prevented from performing its obligations and should only be given if it is satisfied that it can discharge the burden of proof of causation referred to above. This is especially important in the context of the right of either party to terminate the contract if the progress of the Works is delayed for more than a particular period (84 Days in FIDIC). This could allow contracts which have become financially unsound for either party to be terminated under the guise of COVID-19! Strategically, the Party giving the Notice needs to be aware of that threat of that potential.Fifthly, it must be remembered that each party to a FIDIC style contract will be under a contractual duty to &ldquo;use all reasonable endeavors to minimize any delay in the performance of the Contract as a result of Force Majeure.&rdquo; This is a continuing obligation.So what other options are open to the Contractor to recover the costs and losses incurred as a result of the problems of COVID-19?Change in LawSubject to the giving of Notice, the Contractor may be entitled to an extension of time and additional cost if delay and cost are incurred as a result of a Change in Law or changes to the interpretation of such laws. Under FIDIC, &ldquo;Change in Law&rdquo; is broadly defined and actions of the State Governments and Union Territories to invoke Epidemic Diseases Act 1897, and other such Acts to issue Regulations/Ordinances and orders thereunder may well qualify as a &lsquo;Change in Law&rsquo;.Delays caused by AuthoritiesAgain, subject to giving a Notice, the Contractor may be entitled to an extension of time (but no cost) if it has &ldquo;diligently followed&rdquo; procedures laid down by public authorities but those authorities delay or disrupt the Contractor&rsquo;s work. This is likely to apply to the measures enacted to control the spread of COVID-19 by lockdown and stoppage of works etc.Delays by EmployerIf, as is likely, the pandemic has prevented the Employer from giving access or possession to all or part of the Site at any time, or has delayed approvals, release of design information or the provision of Employer supplied materials, these would amount to breaches of contract by the Employer entitling the Contractor to recover costs and extensions of time. To prevent such matters being breaches of contract, the Employer would be advised to claim Force Majeure on the basis that the pandemic and its consequences are preventing him from performing his contractual obligations. If the Employer has not done so, or has done so defectively or not in accordance with the procedures of the Contract, the Contractor may wish to claim breach of contract and thereby recover its costs. It the Employer has properly claimed Force Majeure, the Contractor must be aware of its rights to seek a termination of the Contract after the elapse of the appropriate period of time.Variations and Changes to the WorksThere are a number of provisions in FIDIC style contracts which may be of relevance to matters which have been impacted by COVID-19 and can give rise to additional cost and time.&bull; A variation to the Works necessary to accommodate changes required as a result of taking account of the effect of the pandemic upon the Permanent Works or their means of delivery.&bull; A change to the relevant applicable technical standards, environmental laws, product standards and so on specified by the Employer caused or required as a result of the pandemic may entitle the Contractor to a Variation, with consequent time and cost recovery.&bull; Potentially, changes required by the Employer to the Contractor&rsquo;s Health and Safety Procedures under Clause 6.7 could be argued to require a Variation with the concomitant entitlements.Considerations Going ForwardContractors need to be alert to ensuring that their rights under the Contract to protect themselves from the dire impacts of COVID-19 and its consequences are maintained and implemented. They need to consider the strategic consequences of a Force Majeure claim and the need to give Notice, establish causation, maintain careful records and evidence and provide updates where required. They need to consider carefully whether the events and the Employer&rsquo;s reaction to such events provide an opportunity to claim breach of contract or to seek a Variation. Doing nothing is not an option.Finally, it should be noted that in relation to contracts entered into following the declaration by the WHO of a pandemic (and possibly earlier), the protection of a claim of Force Majeure is unlikely to be available since the requirement of unforseeability will be absent and parties could and should have made provision accordingly in their contracts. Contractors will be advised to ensure that all current and future contracts contain express provisions dealing with the risk of COVID-19 and its consequences. Employers may want COVID-19 expressly carved out from Force Majeure, Suspension and Termination provisions whilst Contractors will be best advised, as a minimum, to require express extension of time provisions. In current negotiations, Contractors should also be seeking additional cost provisions. Whilst a generic entitlement is unlikely to be acceptable to &acirc;&euro;&lsaquo;Employers, Contractors should seek for very specific events of relief for costs in relation to material availability and supply chain issues generally. As the construction sector opens up more, there are likely to be problems of reduced supply chain capacity due to insolvencies and general financial uncertainties; the risk of these need to be evaluated and allocated with clarity and fairness.Consideration should also be given to cash flow improvements such as shorter payment periods, greater advance payments, improved price indexation and reduced retentions. There is much that all sides of the industry need to be doing to ensure that the economic engine of construction continues to drive India&rsquo;s growth.

MANAGING THE IMPACT OF COVID-19 INFRASTRUCTURE & CONSTRUCTION SECTOR

Mother Jones

THE DEMOCRACY BOMB

FOOD FOR THOUGHT - CRIME OF THE CROP

ECONUNDRUMS - CHATBOT QUACKS

Tread

BLOODSHARK

Mac Life

FAST FIXES FOR YOUR MAC

Create your dream smart home

Vogue US

The Dreamlife of Zendaya

Condé Nast Traveler US

home is where you make it

lost in time

EL JEFE

Maximum PC

LIQUID LUNACY: ADVANCED PC COOLING IN 2024

Nvidia's AI Superchip

Cat Talk

Genetic Pleiotropy and the Risks in Breeding Recessive Mutations

Preparing Kittens For the Show Hall

RUNWAY TO SANTA FE

THE COMFORTS OF EXARING

2024 WINTER 4X4 JAMBOREE

A Sense of Occasion

PAINT THE TOWN

BLUUD MONEY

Building a Better Ford-with GM Components

FORGED FILIPINO BOLOS

THIRD TIME'S THE CHARM?

Intel's crazy plan for 1nm silicon

Dragon's Dogma 2

NZXT H6 Flow

THE BUILDS

word of mouth

Not Black and White

States of WONDER

English

Spanish(español)

Bengali(বাঙালি)

Gujarati(ગુજરાતી)

Hindi(हिन्दी)

Malayalam(മലയാളം)

Tamil(தமிழ்)

Telugu(తెలుగు)

Legal Era

If You Think Positive Covid Is A Big Opportunity

PROJECT DEVELOPMENT 

NEW ARBITRATION RULES

M&A in the time of COVID and beyond

SWITZERLAND A DIFFERENTIATED APPROACH TO FRAUD

JOINT VENTURE DISPUTES MEDIATING

Recognition of HONG KONG INSOLVENCY PROCEEDINGS IN MAINLAND CHINA 

CONFIDENTIALITY IN ARBITRATION: RECENT DEVELOPMENTS IN SINGAPORE

ESSENTIAL GOODS SERVICES UNDER IBC 

A BIDEN ADMINISTRATION'S NEW VISION FOR THE AMERICAN WORKPLACE

1. You agree that the use of Magzter.com, the application and its services, are at solely at your own risk. Neither Magzter.com nor its associates nor employees nor third party content providers guarantee that the service will be completely uninterrupted or error-free or foolproof against miscreant activities. Nor do they warranty that you will get the exact results as expected or promised by the website or product.

11. THE SERVICE AND ALL PUBLICATIONS ARE PROVIDED ON AN 'AS IS' AND 'AS AVAILABLE' BASIS. MAGZTER, ITS AFFILIATES, SUPPLIERS, LICENSORS AND AGENTS EXPRESSLY DISCLAIM ALL WARRANTIES OF ANY KIND, WHETHER EXPRESS OR IMPLIED, INCLUDING BUT NOT LIMITED TO THE IMPLIED WARRANTIES OF MERCHANTABILITY, FITNESS FOR A PARTICULAR PURPOSE AND NON-INFRINGEMENT. WITHOUT LIMITING THE FOREGOING, NEITHER MAGZTER NOR ITS AFFILIATES, SUPPLIERS, LICENSORS OR AGENTS, MAKES ANY WARRANTY THAT (I) THE SERVICE WILL MEET YOUR REQUIREMENTS, (II) THE SERVICE WILL BE UNINTERRUPTED, TIMELY, SECURE, OR ERROR-FREE, (III) THE INFORMATION THAT MAY BE OBTAINED FROM THE USE OF THE SERVICE OR THAT MAY BE CONTAINED IN THE PUBLICATIONS WILL BE ACCURATE OR RELIABLE, OR (IV) THE QUALITY OF ANY PUBLICATIONS OR THE SERVICE WILL MEET YOUR EXPECTATIONS. YOU ARE SOLELY RESPONSIBLE FOR OBTAINING AND MAINTAINING RELIABLE INTERNET CONNECTIVITY AND YOUR DEVICE. MAGZTER IS NOT RESPONSIBLE FOR YOUR INABILITY TO DOWNLOAD CONTENT. ANY MATERIAL DOWNLOADED OR OTHERWISE OBTAINED THROUGH THE USE OF THE SERVICE IS DONE AT YOUR OWN DISCRETION AND RISK AND YOU WILL BE SOLELY RESPONSIBLE FOR ANY DAMAGE TO YOUR COMPUTER SYSTEM OR MOBILE DEVICE OR LOSS OF DATA THAT RESULTS FROM THE DOWNLOAD OF ANY SUCH MATERIAL. NO ADVICE OR INFORMATION, WHETHER ORAL OR WRITTEN, OBTAINED BY YOU FROM MAGZTER OR THROUGH OR FROM THE SERVICE SHALL CREATE ANY WARRANTY.

2. You will maintain and promptly update that information to keep it true, accurate, current and complete. You are responsible for maintaining the confidentiality of your account and password and for restricting access to your computer, and you agree to accept responsibility for all activities that occur under your account, including the selection and use of all content and services.

2.You will maintain and promptly update that information to keep it true, accurate, current and complete. You are responsible for maintaining the confidentiality of your account and password and for restricting access to your computer, and you agree to accept responsibility for all activities that occur under your account, including the selection and use of all content and services.

3. In no event will Magzter.com or any person or entity or third party involved in the creation, production and distribution of the content on the website and the application be liable in contract or legally for any damages, including and not limited to, direct, indirect, incidental, special, and consequential incurred to you while or on using Magzter.com. By registering on the website or downloading the application, you agree that the provisions mentioned in this section shall apply to all use of and content on the website and the application.

3. Without prior written or authorised permission from Magzter, you should not modify, copy, distribute or sell any content obtained from Magzter as everything published here is the proprietary property of Magzter or its licensors. As such unauthorised use may also violate applicable laws including copyright and trademark laws, Magzter strictly prohibits these and will terminate your access and account if any such illegal activity is proved or detected. You should also stand liable for the damages caused by these unauthorised activities. Except as permitted by the Publication's lawful owner, you acknowledge that you do not acquire any ownership rights by downloading Publications accessed through the Service. Except as explicitly required under copyright law or permitted by the features of the Service you may not modify, reverse engineer, publish, transmit, display, participate in the transfer or sale, create derivative works of, or in any way commercially exploit or provide to a third party the content of the App, the Publications, or any portion of them without the express permission of Magzter and the owner of such content. We do not grant you any licenses, express or implied, to the intellectual property of Magzter or Magzter's licensors.

5. You specifically acknowledge that Magzter.com is not liable for any kind of defamatory or offensive or illegal conduct of other users or third parties or their content and that the risk of injury from the foregoing rests entirely with you.

8. Magzter reserves all rights to monitor the content published and inputted by you for the purpose of determining whether you are compliant with these terms and conditions and other operating rules determined by Magzter. Magzter has the right to take decisions about the content and delete them at its own will.

9. Magzter is a distributor and NOT a publisher of the Publications and so Magzter has no editorial control over the content, including opinions, advice, statements, services, offers etc., that is represented in the magazines. So Magzter will not take responsibility for the accuracy or the reliability for any information or facts provided therein or that is made available through the service, by anyone other than authorised Magzter employees who are acting on their official capacities. Accordingly, we have no editorial control over the Publications. Any opinions, advice, statements, services, offers or other information or content expressed or made available by third parties, including those made in Publications offered by the Service, are those of the respective author(s) or publisher(s) and not of Magzter. Magzter will not be liable for any loss or damage caused by your reliance on information obtained through the Service or from the Publications. The Service may contain links to other Internet sites and third-party resources and Magzter does not assume any responsibility or liability for communications or materials available at such linked sites. These links are provided for your convenience only. You are solely responsible for understanding any terms and conditions that may apply when you visit or place an order through a third-party site.

Details of the objectionable content, including its link on our platform

Download your favorite titles and read them offline, anytime and anywhere

Gift your loved ones with a Magzter Gift Card instantly and give them the freedom to read their favorite magazines and newspapers from thousands of best-selling titles.

Gift your loved ones with a Magzter Gift Card instantly and give them the freedom to read their favorite magazines from thousands of best-selling titles.

Gift your loved ones with a Magzter Gift Card instantly and give them the freedom to read their favorite magazines from {{magCount}} best-selling international titles.

Girish Ramdas is the Co-founder and CEO of Magzter, a New York based startup that has been making waves in the global digital publishing business. Magzter has crossed 80 million users since its inception in 2011 from more than 150+ countries with 1000s of magazines, newspapers and books from more than 4,500 publishers worldwide. He has more than 25 years of experience in cross-platform publishing, including print, mobile, and Web development. During this period, he has co-founded and run three successful start-up businesses. He has enabled magazine companies to go digital and helps them monetize their content across the digital world. Girish's deep industry experience in online, mobile and publishing ecosystems has made him an expert in acquisition, marketing and monetizing digital content across platforms globally.

In the event that you encounter any objectionable content on our platform, we have put in place a grievance redressal policy to address your concerns.

Magzter Inc. (“Company”, “we”, “us” or “our”) knows that you care about how your personal information is used and shared. Please read the following privacy policy (the “Policy”) to learn more about our privacy practices. By visiting any of the websites operated by the Company, and any sub-domains thereof, or using any of our mobile applications and other methods of content distribution (collectively, the “Service”), you acknowledge that you accept the practices and policies outlined in this Policy, and you hereby consent that we will collect, use, and share your information in the following ways.

Magzter Inc. is the World's largest and fastest growing self-service, cross-platform digital newsstand with over 80 million users since its inception in 2011 and thousands of magazines and newspapers across 40+ categories and 60+ languages. Headquartered in New York, Magzter has its local presence in Amsterdam, London, Mexico City, Chennai, Mumbai, New Delhi, Bengaluru, Singapore, and will soon be expanding to other countries. Founded by global entrepreneurs, Girish Ramdas and Vijay Radhakrishnan in June 2011, Magzter enables magazine and newspaper publishers around the world to create and deliver digital editions of their titles to global consumers.

Magzter is committed to providing a safe and secure platform for our users. Please note that Magzter is merely a platform for publishers to distribute their content. We do not control or endorse the content published on our platform. We cannot be held responsible for the actions of our publishers or their content.

Magzter is not responsible for compensating any party that has suffered damages or incurred costs due to any content, or part of the content, that violates their rights. Magzter is not liable to face any legal action in civil court for any violation of rights caused by any content, or part of the content, that infringes the rights of a third party.

Magzter offers the world’s largest {{allyoucanread}} subscription service called {{gold}} which gives digital readers unlimited access to 8,500+ magazines and newspapers for a monthly subscription price. Magzter also has the largest number of stories in the world with its game-changing ezRead 2.0 feature for its apps, which enables smartphone and small-screen mobile users to enjoy magazine content the way it was meant to be enjoyed, with article text that is easy to read and is accompanied by stunning videos and high resolution photography.

Magzter offers the world’s largest “All-You-Can-Read” subscription service called Magzter GOLD which gives digital readers unlimited access to 8,500+ magazines and newspapers for a monthly subscription price. Magzter also has the largest number of stories in the world with its game-changing ezRead 2.0 feature for its apps, which enables smartphone and small-screen mobile users to enjoy magazine content the way it was meant to be enjoyed, with article text that is easy to read and is accompanied by stunning videos and high resolution photography.

Name

Note: This will only share the cover and the publication information, but not the content.

Please fill out this form if you need any help regarding publishing your content on Magzter

Prior to Magzter, he was the President of Dot Com Infoway (DCI) and Galatta Media. His duties included strategic marketing, partnership development, and monetizing content globally. DCI grew from a small team of 3 in 2000 to 300 by 2011 and was dealing with web, software and app development for clients globally.

Since we launched, Magzter has been committed to partnering with global organizations to provide the greatest possible newsstand technology & service to our customers. Whether you are looking to offer magazine subscriptions to your customer database or just want to learn more, Magzter is committed to helping your business grow. To find out more, please fill out the questionnaire below:

The DMCA allows us to restore the removed content if the party filing the original DMCA Notice does not file a court action against you within ten business days of receiving the copy of your Counter Notice.

This Policy covers Company’s treatment of personally identifiable information (“Personal Information”) and other information about you and your computer or device that Company gathers when you are accessing the Service. We may collect Personal Information from you, as explained in more detail below, and we use this Personal Information internally in connection with our Services, including to personalize, provide, and improve our products, services, content, and advertising, and to allow you to set up a user account and profile, to contact you, to fulfill your requests for certain products and services, and to analyze how you use the Services. In certain cases, we may also share some Personal Information with third parties, but only as described in point 4.

This title is included with your Magzter GOLD subscription

To analyze the quality of content and provide appropriate feedback to publishers

We have designated a Grievance Officer to address any complaints related to objectionable content.

We request that any complaint related to objectionable content be sent to the Grievance Officer through email to the above-mentioned email address. We also request that you provide the following details when making a complaint:

and the App that provides you the capability to order, subscribe to and receive the delivery of various magazines, books, news and magazine and publication related content (collectively known as 'Publications') and to have these digital versions of the Publications delivered to you

c. We also collect information associated with your use of the application in order to make personalized recommendations. If you provide your third-party account credentials to us, you understand some content and/or information in those accounts (“Third Party Account Information”) may be transmitted into your account with us if you authorize such transmissions, and that Third Party Account Information transmitted to the Service is covered by this Policy.

f. The Personal Information we collect allows us to respond to your requests, improve our products and services, customize the advertising and content you see, and communicate with you about new products.

is the World's largest and fastest growing self-service, cross-platform digital newsstand with over 87 million users since its inception in 2011 and thousands of magazines and newspapers across 40+ categories and 60+ languages. Headquartered in New York, Magzter has its local presence in Amsterdam, London, Mexico City, Chennai, Mumbai, New Delhi, Bengaluru, Singapore, and will soon be expanding to other countries. Founded by global entrepreneurs, Girish Ramdas and Vijay Radhakrishnan in June 2011, Magzter enables magazine and newspaper publishers around the world to create and deliver digital editions of their titles to global consumers.

n. We will also use usage information in order to ensure users adhere to our Terms of Use. For example, a user’s usage information will help us confirm that a user only downloads a magazine or other content a permitted number of times or to a permitted number of devices.

which gives digital readers unlimited access to 8,500+ magazines and newspapers for a monthly subscription price. Magzter also has the largest number of stories in the world with its game-changing ezRead 2.0 feature for its apps, which enables smartphone and small-screen mobile users to enjoy magazine content the way it was meant to be enjoyed, with article text that is easy to read and is accompanied by stunning videos and high resolution photography.

{{magzter}} is the World's largest and fastest growing self-service, cross-platform digital newsstand with over 87 million users since its inception in 2011 and thousands of magazines and newspapers across 40+ categories and 60+ languages. Headquartered in New York, Magzter has its local presence in Amsterdam, London, Mexico City, Chennai, Mumbai, New Delhi, Bengaluru, Singapore, and will soon be expanding to other countries. Founded by global entrepreneurs, Girish Ramdas and Vijay Radhakrishnan in June 2011, Magzter enables magazine and newspaper publishers around the world to create and deliver digital editions of their titles to global consumers.